Braes of Doune Wind Farm (Scotland) Ltd v Alfred McaLpine Business Services Ltd, Court of Appeal - Technology and Construction Court, March 13, 2008, [2008] EWHC 426 (TCC),[2008] 1 Lloyd's Rep 608,[2008] 1 CLC 487,[2008] BLR 321,[2008] 2 All ER (Comm) 493,[2008] Bus LR D137 - Case Law - VLEX 53012156

Braes of Doune Wind Farm (Scotland) Ltd v Alfred McaLpine Business Services Ltd, Court of Appeal - Technology and Construction Court, March 13, 2008, [2008] EWHC 426 (TCC),[2008] 1 Lloyd's Rep 608,[2008] 1 CLC 487,[2008] BLR 321,[2008] 2 All ER (Comm) 493,[2008] Bus LR D137

FREE EXCERPT

Neutral Citation Number: [2008] EWHC 426 (TCC)

Case No: HT 08 07

IN THE HIGH COURT OF JUSTICE

QUEEN'S BENCH DIVISION

TECHNOLOGY AND CONSTRUCTION COURT

Royal Courts of Justice

Strand, London, WC2A 2LL

Date: 13th March 2008

Before :

MR JUSTICE AKENHEAD

- - - - - - - - - - - - - - - - - - - - -

Between :

| |BRAES OF DOUNE WIND FARM (SCOTLAND) LIMITED |Claimant |

| |- and - | |

| |ALFRED MCALPINE BUSINESS SERVICES LIMITED |Defendant |

- - - - - - - - - - - - - - - - - - - - -

- - - - - - - - - - - - - - - - - - - - -

David Sears QC and Serena Cheng (instructed by Shepherd and Wedderburn) for the Claimant

Andrew Bartlett QC (instructed by Dundas & Wilson LLP) for the Defendant

Hearing dates: 13 February 2008

- - - - - - - - - - - - - - - - - - - - -

JUDGMENT

Mr. Justice AKENHEAD:

Introduction

1. There are two applications before the Court relating to the First Award of an arbitrator, Mr John Uff CBE QC. This award relates to an EPC (Engineering, Procurement and Construction) Contract dated 4 November 2005 (“the EPC Contract”) between the Claimant (“the Employer”) and the Defendant (“the Contractor”) whereby the Contractor undertook to carry out works in connection with the provision of 36 wind turbine generators (the “WTGs”) at a site some 18 kilometres from Stirling in Scotland. This award deals with the enforceability of the clauses of the EPC Contract which provided for liquidated damages for delay.

2. The Claimant applies for leave to appeal against this award upon a question of law whilst the Defendant seeks in effect a declaration that this Court has no jurisdiction to entertain such an application and for leave to enforce the award.

3. I will deal first with the issue of jurisdiction.

Jurisdiction

4. The issue here arises out of the application of Section 2 of the Arbitration Act 1996:

“(1) The provisions of this Part apply where the seat of the arbitration is in England and Wales or Northern Ireland”.

The seat of the arbitration is identified in Section 3 as being the “juridical seat” of the arbitration “designated by the parties to the arbitration agreement”. If the juridical seat of the arbitration was in Scotland, the English Courts have no jurisdiction to entertain an application for leave to appeal. The Contractor argues that the seat of the arbitration was Scotland whilst the Employer argues that it was England.

5. There were to be two contractors involved with the project. Whilst Vestas-Celtic Wind Technology Limited was to design, supply, construct and install the 36 WTGs themselves, the Contractor was to design and carry out the bulk of the remaining works such as the foundations for the WTGs, other civil and building works, electrical works connecting the WTGs to the switch room and other connection works. There was an “Interface Agreement” between the Contractor, the Employer and the Wind Turbine Contractor.

6. The material clauses of the EPC Contract were:

“1.4.1. The Contract shall be governed by and construed in accordance with the laws of England and Wales and, subject to Clause 20.2 [Dispute Resolution], the Parties agree that the courts of England and Wales have exclusive jurisdiction to settle any dispute arising out of or in connection with the Contract.

20.2.2. (a) …any dispute or difference between the Parties to this Agreement arising out of or in connection with this Agreement shall be referred to arbitration.

(b) Any reference to arbitration shall be to a single arbitrator…and conducted in accordance with the Construction Industry Model Arbitration Rules February 1998 Edition, subject to this Clause (Arbitration Procedure)…

(c) This arbitration agreement is subject to English Law and the seat of the arbitration shall be Glasgow, Scotland. Any such reference to arbitration shall be deemed to be a reference to arbitration within the meaning of the Arbitration Act 1996 or any statutory re-enactment.”

7. The Arbitration Rules, known colloquially as the “CIMAR Rules” provided as follows:

“1.1 These Rules are to be read consistently with the Arbitration Act 1996 (the Act), with common expressions having the same meaning. Appendix 1 contains definitions of terms. Section numbers given in these Rules are references to the Act.

1.2 The objective of the Rules is to provide for the fair, impartial, speedy, cost-effective and binding resolution of construction disputes, with each party having a reasonable opportunity to put his case and deal with that of his opponent. The parties and the arbitrator are to do all things necessary to achieve this objective: see Sections 1 (General Principles), 33 (General duty of the tribunal) and 40 (General duty of parties).

1.4 The arbitrator has all the powers and is subject to all the duties under the Act except where expressly modified by the Rules.

1.5 Sections of the Act which need to be read with the Rules are printed in the text. Other Sections referred to in the text are printed in Appendix II.

1.6 These rules apply where:

(a) a single arbitrator is to be appointed, and

(b) the seat of the arbitration is in England and Wales or Northern Ireland.

1.7 These rules do not exclude the powers of the Court in respect of arbitral proceedings, nor any agreement between the parties concerning those powers.

4.1 The arbitrator has the power set out in Section 30

4.2 The arbitrator has the powers set out in Section 37…

4.3 The arbitrator has the powers set out in Section 38(4) to (6)…”

In Appendix I the “Act” was defined to mean the Arbitration Act 1996.

8. One must seek to construe the EPC Contract having regard to all its material terms. It is only if there is some irreconcilable ambiguity that one will have to have regard to other principles.

9. I do bear in mind that, in the absence of clear wording, the parties are unlikely to have wished to exclude this or the Scottish Courts’ powers of control and intervention. I was told by the parties in argument that the Scottish Courts’ powers of control and intervention would be, at the very least, seriously circumscribed by the parties’ agreement in terms as set out in Paragraph 6 above. Mr Bartlett QC indicated to me that the Scottish Courts’...

To continue reading

REQUEST YOUR FREE TRIAL